Supreme Court · 2006 INSC 987 · Decided 11 December 2006
Ramnath International Construction PVT. LTD. v. Union of India and ANR.
- Court
- Supreme Court of India
- Citation
- 2006 INSC 987 · [2006] SUPP. 10 S.C.R. 570
- Case number
- CIVIL APPEAL No. 3167/2005
- Decided
- 11 December 2006
- Bench
- H.K. SEMA, R.V. RAVEENDRAN (2-judge bench)
- Outcome
- Dismissed
- Case type
- Civil
Headnote
INTERNATIONAL CONSTRUCTION PVT. LTD. B v. UNION OF INDIA AND ANR. DECEMBER I I, 2006 [H.K. SEMA AND R.V. RA VEENDRAN,JJ.) Arbitration-Contract-Delay in execution partly on account of employer-Claim of compensation by contractor-Terms of contract bearing C claim of compensation on account of respect of certain items was in derogation of the terms of the contract-On appeal, held: The claim for compensation in respect of certain items of contract on account of delay was barred by the terms of the D Contract-Award ignoring the term of contract was made in excess of jurisdiction-The
Judgments are the courts' own published copies, provided for study; they are not certified copies. Source: Indian Supreme Court & High Court Judgments, Dattam Labs (CC-BY-4.0)