Supreme Court · 2024 INSC 628 · Decided 23 August 2024
Pam Developments Private Limited v. The State of West Bengal & ANR.
- Court
- Supreme Court of India
- Citation
- 2024 INSC 628 · [2024] 8 S.C.R. 615
- Case number
- CIVIL APPEAL No. 9781/2024
- Decided
- 23 August 2024
- Bench
- PAMIDIGHANTAM SRI NARASIMHA, PANKAJ MITHAL (2-judge bench)
- Case type
- Civil
- Acts & sections cited
- Arbitration Act Section 34, 37, 37(1)
Headnote
Matter pertains to the arbitral award in favour of the contractor as regards labour charges for uneconomical stoppage of work, interest on delayed payment, and interest, upheld by the District Judge but set aside/modified by the High Act, 1996 - ss. 34 and 37 - Arbitral awards - Work contract - Claims raised by the contractor under different heads alleging delays on the part of the State, referred to the arbitrator - Arbitral award in favour of the contractor under heads-loss of
Judgments are the courts' own published copies, provided for study; they are not certified copies. Source: Indian Supreme Court & High Court Judgments, Dattam Labs (CC-BY-4.0)