Supreme Court · 1989 INSC 10 · Decided 16 January 1989
P. M. Paul v. Union of India
- Court
- Supreme Court of India
- Citation
- 1989 INSC 10 · [1989] 1 S.C.R. 115
- Case number
- CIVIL APPEAL No. 2632/1987
- Decided
- 16 January 1989
- Bench
- SABYASACHI MUKHERJI, S. RANGANATHAN (2-judge bench)
- Outcome
- Disposed off
- Case type
- Civil
- Acts & sections cited
- Arbitration Act Section 14, 17, 30, 33, 5
Headnote
B -{ Arbitration Act 1940: Sections 14, 17, 30 and 33-Award­ Setting aside of-Whether arbitrator has misconducted himself or proceedings-Adjudicating upon matter not subject matter of adjudica­ tion-Legal misconduct. The appellant, a contractor entered into a contract with the respondent the phases was March 10, 1979, the date of completion of Phase I was June 9, 1980 and that of Phase II was November 9, 1980. Dispute arose about the handing over of the site. The appellant's case was that the site was not handed over as stipulated and consequently the work could not either be
Judgments are the courts' own published copies, provided for study; they are not certified copies. Source: Indian Supreme Court & High Court Judgments, Dattam Labs (CC-BY-4.0)