Supreme Court · 2023 INSC 931 · Decided 19 October 2023
M/S Unibros v. All India Radio
- Court
- Supreme Court of India
- Citation
- 2023 INSC 931 · [2023] 14 S.C.R. 683
- Case number
- CIVIL APPEAL No. 6895/2023
- Decided
- 19 October 2023
- Bench
- S. RAVINDRA BHAT, DIPANKAR DATTA (2-judge bench)
- Outcome
- Dismissed
- Case type
- Civil
- Acts & sections cited
- Arbitration Act Section 34(2)(b)
Headnote
HEADNOTES Issue for consideration: Arbitral award in question if in confl ict with the public policy of India and; whether a claim on account of loss of profi t is liable to succeed merely on the ground that there has been delay in the execution of the construction contract, attributable to Act, 1996 - s.34(2)(b) - "Public policy of India" - Appellant awarded work contract by the respondent - Disputes between the parties owing to the delay in work, referred to Arbitrator - Vide First Award, appellant was awarded sum towards loss of
Judgments are the courts' own published copies, provided for study; they are not certified copies. Source: Indian Supreme Court & High Court Judgments, Dattam Labs (CC-BY-4.0)