Supreme Court · 2011 INSC 510 · Decided 21 July 2011
M/S. MSK Projects (I) (Jv) LTD v. State of Rajasthan & ANR.
- Court
- Supreme Court of India
- Citation
- 2011 INSC 510 · [2011] 9 S.C.R. 402
- Case number
- CIVIL APPEAL No. 5416/2011
- Decided
- 21 July 2011
- Bench
- P. SATHASIVAM, B.S. CHAUHAN (2-judge bench)
- Outcome
- Disposed off
- Case type
- Civil
- Acts & sections cited
- Arbitration Act Section 3
Headnote
Contract: c Construction of a bypass road - Concession agreement authorising contractor to collect toll fee - Dispute between parties as to delay in issuance of notification by State Government barring the use of old route as also entitlement of contactor to collect toll fee from vehicles using of the road - Arbitral tribunal holding that there had .. been delay on the part of the State in issuing the notification and the State failed to implement the same and the contractor was entitled to collect fee even from vehicles using the specific patch of the road - District Judge and High
Judgments are the courts' own published copies, provided for study; they are not certified copies. Source: Indian Supreme Court & High Court Judgments, Dattam Labs (CC-BY-4.0)