Supreme Court · 2009 INSC 1113 · Decided 7 September 2009
M/S Asian Techs LTD. v. Union of India & Others
- Court
- Supreme Court of India
- Citation
- 2009 INSC 1113 · [2009] 14 S.C.R. 182
- Case number
- CIVIL APPEAL No. 311/2003
- Decided
- 7 September 2009
- Bench
- MARKANDEY KATJU, A.K. GANGULY (2-judge bench)
- Outcome
- Appeal(s) allowed
- Case type
- Civil
- Acts & sections cited
- Arbitration Act
Headnote
..t. Arbitration: c Jurisdiction of arbitrator - Appellant-contractor entered · into works contract with respondents - Material alteration and addition in work done at the instance of respondents - Consequent delay in execution of contract - Dispute over D claim raised by appellant in contract ·--r invoked - Arbitrator passed non-speaking award in favour of appellant - Decree passed in terms of the award - Set aside by High Court on ground that the arbitrator travelled beyond the. terms of reference - Propriety of - Held: Not prQper - E On facts, delay in execution of
Judgments are the courts' own published copies, provided for study; they are not certified copies. Source: Indian Supreme Court & High Court Judgments, Dattam Labs (CC-BY-4.0)