Supreme Court · 2025 INSC 574 · Decided 28 April 2025
Consolidated Construction Consortium Limited v. Software Technology Parks of India
- Court
- Supreme Court of India
- Citation
- 2025 INSC 574 · [2025] 4 S.C.R. 1846
- Case number
- CIVIL APPEAL No. 5383/2024
- Decided
- 28 April 2025
- Bench
- ABHAY S. OKA, UJJAL BHUYAN (2-judge bench)
- Outcome
- Dismissed
- Case type
- Civil
- Acts & sections cited
- Contract Act Section 55, 73, 74; Arbitration Act Section 34, 37
Headnote
Issue arose as regards the correctness of the order passed by the Division Bench of High Court upholding the arbitral award. Arbitration and Conciliation Act, 1996 - ss.34 and 37 - Application for setting aside arbitral awards - regarding delay in completion of the construction contract - Respondent-contracting authority deducted liquidated damages from the contractual dues of the appellant-contractor, along with other deduction and paid balance amount to appellant - Initiation of arbitral proceedings by
Judgments are the courts' own published copies, provided for study; they are not certified copies. Source: Indian Supreme Court & High Court Judgments, Dattam Labs (CC-BY-4.0)