Supreme Court · 2023 INSC 850 · Decided 21 September 2023
Batliboi Environmental Engineers Limited v. Hindustan Petroleum Corporation Limited and Another
- Court
- Supreme Court of India
- Citation
- 2023 INSC 850 · [2023] 12 S.C.R. 441
- Case number
- CIVIL APPEAL No. 1968/2012
- Decided
- 21 September 2023
- Bench
- SANJIV KHANNA, M.M. SUNDRESH (2-judge bench)
- Outcome
- Dismissed
- Case type
- Civil
- Acts & sections cited
- Arbitration Act Section 37
Headnote
HEADNOTES Issue for consideration: Whether the Division Bench of the High Court was justifi ed in allowing the appeal fi led by the respondents u/s. 37 of the Arbitration and Conciliation Act, 1996, and thereby setting aside the and Conciliation Act, 1996 - s. 37 - Arbitral award - Interference with - Award of turnkey contract to the appellant by the respondents for a contract value to be completed within stipulated period - Delay in project completion which was extended, and thereafter
Judgments are the courts' own published copies, provided for study; they are not certified copies. Source: Indian Supreme Court & High Court Judgments, Dattam Labs (CC-BY-4.0)